Skip to main content
Open Source Software Installation Agreement Concepts
What's Included
$19 Template
$89 Pack
$199 Pro
This single static template
 
 
 
180 contract template library
 
 
 
Starter proposal template library
 
 
 
Novice quoting software
 
 
 
340 contract templates
 
 
 
700 proposal layouts
 
 
 
200 completed sample proposals
 
 
 
110 project templates
 
 
 
Expert quoting software
 
 
 
Document branding features
 
 
 

How to write your Open Source Software Installation Agreement

We include this 4 page template with IT/Software/Hardware Contract Pack and the Proposal Kit Professional. You will get more content and software automation for data merging, managing client documents, and creating proposals with line item quoting with a Contract Pack or the Professional.

Supported Operating Systems LogosDOWNLOADABLE, ONE-TIME COST, NO SUBSCRIPTION FEES
The Open Source Software Installation Agreement is used for software installation projects that are based on using Open Source components. It is used when installing third party open source software on a customer's computer, web site, or network. This software contract includes clauses specific to the use of third party open source products.
Document Length: 4 Pages
Quote Logo What Our Clients Say

Contract Pack Professional has helped me from the beginning. It doesn’t matter whether we have a client that is a family friend or a brand new client; we always send them a contract. It is so important to act professional from the beginning."

Laura Fedock
Elle-Design

1. Get IT/Software/Hardware Contract Pack or the single template that includes this business contract document.

We include this Open Source Software Installation Agreement in editable Word format that can be customized using your office software.

2. Download and install after ordering.

Once you have ordered and downloaded your template or pack, you will have all the content you need to get started.

3. Customize the contract template with your information.

You can customize the contract document as much as you need. If you get a Contract Pack or Professional Bundle, you can also use the included Wizard software to automate name/address data merging.

Open Source Software Installation Agreement

Writing the Open Source Software Installation Agreement document

SOFTWARE INSTALLATION AGREEMENT - OPEN SOURCE

THIS AGREEMENT is made this Current Day day of Current Month, Current Year, by and between Company Name (hereafter referred to as "Customer") and Company Name (hereafter referred to as "Company"). The purpose of this Software Installation Agreement is to set forth a contract arrangement under which Company will provide a fully licensed copy of Insert software, application or suite name ("The Software Project") and Installation Services for a single desktop, network, target domain or web server for Customer.

In consideration of the mutual covenants set forth in this Agreement, Customer and Company hereby agree as follows:

Installation of the Software Project

Customer agrees to compensate Company according to the terms listed on Exhibit A attached hereto.

Specifications

Company agrees to develop the Software Project pursuant to the specifications set forth in Exhibit B attached hereto (the "Specifications").

Delivery of Software Project

Company will use reasonable diligence in the development of the Software Project and endeavor to deliver to Customer operational Software Project files as soon as possible. Customer acknowledges, however, that this delivery deadline and the other payment milestones listed in Exhibit A are estimates, and are not required delivery dates. Company will make every effort to advise Customer of any delays in advance and seek Customer feedback in regard to the proposed timeline as the development process progresses.

License and Ownership Rights

Company grants Customer a world-wide, non-exclusive right to use, in whole or in part, the Software Project on a single web site domain or server. No additional compensation or license fees shall be required of Customer after the installation is complete. Company shall retain its ownership in (1) all rights, title, and interest in all pre-existing works, interfaces, navigational devices, menus, menu structures, or arrangements, icons, help and other operational instructions, and all other components of any source or object computer code that comprises the Software Project, (2) all pre-existing literal and non-literal expressions of ideas ("Company's Style") that operate, cause, create, direct, manipulate, access, or otherwise affect the Content, and (3) all other pre-existing or proprietary copyrights, patents, trade secrets, and other intellectual or industrial property rights in the Software Project or any component or characteristic thereof. Customer shall not do anything that may infringe upon or in any way undermine Company's rights, title, and interest in the Software Project, as described in this paragraph 4.

Notwithstanding the above, Customer shall retain all of its intellectual property rights in any text, images, or other components it owns and delivers to Company for use in the Software Project, in addition to the physical presence of the site itself. Customer shall be provided with a copy of all installation files and code that comprises or makes up the Software Project as a part of this agreement.

Proprietary Information

Proprietary information exchanged hereunder shall be treated as such by both Company and Customer. This information shall include, but not be limited to, the provisions of this Agreement, and both parties' product(s), services information, and pricing. Customer further agrees to not decompose, disassemble, decode, or reverse engineer any Company-owned program, code, or technology delivered to Customer, or any portion thereof.

Warranty

Company is not responsible for defects caused by changes or issues resulting from third party tools or applications it does not have direct control over, including but not limited to: web browsers, operating systems (OS), plug-ins, extensions, software programs, applets, newly discovered vulnerabilities, scripts, or other items.

1 No Warranty for Outcome or Use of the Software Project

Company makes no warranties or representations of any kind, whether expressed or implied, for the suitability or the outcome from the use of the service it is providing. Company also disclaims any warranty of merchantability or fitness for any particular purpose and will not be responsible for any damages that may be suffered by Customer, including loss of data resulting from delays, non-deliveries or service interruptions by any cause or errors or omissions. Use of any information or results obtained is at Customer's own risk, and Company specifically denies any responsibility for the accuracy or quality of information obtained through its services.

Any connection speed or application execution speed for end users is not guaranteed. Company specifically denies any responsibilities for any damages arising as a consequence of any unavailability.

Open Source Disclaimer

Customer acknowledges that the some of the solutions and libraries being provided by Company are "Open Source" and Customer is being granted a worldwide, non-exclusive license, under the General Public License (GPL) to deploy, modify, or otherwise use the Open Source Code in their business or enterprise. Customer is not being charged a fee for using any open source resources; rather they are paying a fee for the installation service and custom coding provided by Company. The use of Open Source software carries NO WARRANTY, whether explicit or implied, and Company is not responsible for any damages that may be incurred as a result of using Open Source software, libraries, or other resources.

1 Critical Patches, Upgrades, and Security Risks

Customer acknowledges and understands that from time to time vulnerabilities may be uncovered in the Software Project or the operating system, applications, or other programs or resources that the Software Project may be dependent upon to function. Customer acknowledges that it is not Company's responsibility to support, upgrade, or otherwise patch the Software Project after installation is complete.

Disputes

If legal proceedings are commenced to resolve a dispute arising out of or relating to this agreement, the prevailing party shall be entitled to recover all costs, legal fees, and expert witness fees, as well as any costs or legal fees in connection with any appeals.

Indemnification

Customer shall indemnify and hold Company harmless from and against any and all claims, judgments, awards, costs, expenses, damages, and liabilities (including reasonable attorney fees) of whatsoever kind and nature that may be asserted, granted, or imposed against Company directly or indirectly arising from or in connection with Customer's marketing or support services of the Software Project or services or the unauthorized representation of the Software Project and services or any breach of this Agreement by Customer. Customer warrants that everything it gives Company is legally owned or licensed to Customer. Customer agrees to indemnify and hold Company harmless from any and all claims brought by any third party relating to any aspect of the Software Project, including but without limitation, any and all demands, liabilities, losses, costs and claims, including attorney's fees, arising out of injury caused by Customer's products/services, material supplied by Customer, copyright infringement, and defective products sold via the Software Project.

Use of Software Project for Promotional Purposes

Customer grants Company the right to reference the Software Project for promotional purposes and/or to cross-link to it with other marketing efforts developed by Company. Company may not, at any time, disclose or grant access to Customer's Software Project, private information, resources, or any other non-public asset used for the purposes of promotion or marketing.

No Responsibility for Theft

Company has no responsibility for any third party taking, stealing, "hacking," altering, or otherwise modifying all or any part of the Software Project, Source Code, Object Code, Graphics, Text, or any other materials related to the Software Project.

Right to Make Derivative Works

Company has exclusive rights in making any derivative works of pre-existing or open source code or related graphics and animations. Customer acknowledges that similarities may exist between other Software Projects developed by Company and any such similarities, both past and future, constitute Company's Style and proprietary information.

Identification of Company

Customer agrees that Company's links will be placed on the bottom of the front page and on internal pages of the Software Project in a mutually agreeable size and location. Customer also agrees to put Company's copyright notices in any source code where pre-existing or proprietary information is present. Source code copyrights shall not be public unless a user views the source code directly. Customer agrees to display all legally required copyright notices as prescribed by applicable law.

General

If any provision of this Agreement is held to be unenforceable, the enforceability of the remaining provisions shall in no way be affected or impaired thereby. A failure by any party to exercise or delay in exercising a right or power conferred upon it in this Agreement shall not operate as a waiver of any such right or power.

The complete Open Source Software Installation Agreement - with the actual formatting and layout - is available as a single template or as part of a library of related templates in a Contract Pack or the Professional Bundle.
Product name:
Open Source Software Installation Agreement
Produced by:
Proposal Kit
Category:
Software › Computer Software › Business & Productivity Software
Price:
$19 USD
Code:
CT-136
 
 
Proposal Kit Reviews Logo4.7 stars, based on 838 reviews

Key Takeaways

  • The Open Source Software Installation Agreement is available as a ready-to-edit template.
  • The Contract Packs and Professional Bundle include many related agreements and documents.
  • You can automate financials and data merging into contracts using a Contract Pack or Professional Bundle.
  • You can also create business proposals and integrate your contracts using the Professional Bundle.
  • There are no ongoing subscription fees. You get lifetime unlimited use.
Proposal Kit LogoPublished by Proposal Kit, Inc.

Disclaimers

Proposal Kit, Inc. makes no warranty and accepts no responsibility for the suitability of any materials to the licensee's business. Proposal Kit, Inc. assumes no responsibility or liability for errors or inaccuracies. Licensee accepts all responsibility for the results obtained. The information included is not legal advice. Names in use cases have been fictionalized. Your use of the Open Source Software Installation Agreement template and any purchased packages constitutes acceptance and understanding of these disclaimers and terms and conditions.

© 1997 - 2024, Proposal Kit, Inc. All rights reserved. Privacy Policy.